Terms of service

All orders placed imply acceptance of the following terms and conditions:

In these conditions:

a) “Company” refers to Gary Woodpecker and its range of products, employees, representatives, servants, contractors, or agents, who are the sellers of the goods.

b) “Purchaser” refers to the purchaser of goods or services.

c) “Goods” refers to all products and, if applicable, any services provided by the Company to the Purchaser.

• Prices are quoted in the currency relevant to the country of sale and are firm for 14 days unless a deposit is paid in advance.

• All goods are offered solely on the basis of goods supply unless otherwise specified in writing and are not sold under a franchise agreement or implied franchise agreement.

• If any, all, or part of this contract or products mentioned herein are subject to any other taxes or duties at any time, the Purchaser accepts full liability for any and all such taxes and duties.

• Installation or disassembly is not covered by warranty unless authorized by the supplier.

• All repairs will be carried out according to our approved standards.

• Any warranties/licenses offered or implied for any purchased goods are limited to the manufacturer’s standard warranties/licenses only and are subject to the terms and conditions of such warranties unless otherwise specified in writing.

• Goods are provided on the basis that the Purchaser has independently determined the suitability of the goods for the purchaser’s intended purposes and/or usage.

• No freight or transport costs are covered by the supplier unless agreed upon beforehand or included in the initial delivery.

• In no event shall the Company be liable to the Purchaser or any third party for any direct, indirect, incidental, or consequential loss or damages of any nature, except where liability is non-excludable by legislation.

• All faults must be reported before installation.

• The remedies of the Purchaser set forth herein are exclusive, and the total potential liability of the Company shall not exceed the purchase price of the goods or products upon which liability is based.

• All efforts are made regarding paint and selection. Variations in final color are at the manufacturer’s discretion.

• Repairs, if required, will be carried out within a commercially acceptable timeframe.

• A 30% fee applies to the full purchase price for all cancelled orders.

• All prices and specifications are supplied from various manufacturers and distributors’ literature and are subject to change without prior notice.

• All returns must be sent back to our manufacturing base. Goods must be packaged in their original state of arrival or equivalent, and the client is responsible for all freight and packaging charges.

• Due to rapid changes in technology and other variables, specifications are subject to change without prior notice.

• These terms and conditions supersede any prior agreements between the parties. Each provision hereof is severable, and if any provision is held invalid or unenforceable, the remaining provisions shall remain in full force and effect.

• Delivery dates quoted are approximate.

• The customer is responsible for providing all necessary facilities for the easy maneuverability, unloading, and installation of the product upon delivery.

• Manufacturing, depending on build specifications, may take 10-12 weeks, excluding delivery, customs clearances, and public holidays.

• All individual custom designs that cannot be returned to stock are limited to repair only.

• The purchaser enters into a binding agreement upon payment of full or part deposit of 50% and has acknowledged the terms and conditions of this document. Balance payable prior to shipment.

• The company reserves the right to pursue the balance of any deposit not totaling 50% of the invoice price.

• An 18% interest charge will apply to any outstanding amounts.

• The Company will not be liable for any loss incurred as a result of delay or failure to meet an accepted order or to observe any of these terms and conditions due to an event of force majeure.

• These General Conditions are governed by the laws of Poland. Disputes arising from these Terms & Conditions are subject to the exclusive jurisdiction of the courts of Gdansk in Poland

• This document is subject to copyright and cannot be copied or transmitted in part or whole without written permission.

• Liability is limited to repair or replacement within a commercially reasonable time.

• Freight to the point of origin and return is not included.

• All faults must be reported within 48 hours after delivery.

• Freight damage must be documented with accompanying photos, and best efforts will be made to rectify any issues.

• No repairs or modifications are to be made without prior consent.

• All cancelled orders will incur administrative fees to cover CAD drawings that have been issued.

• All prices quoted are for supply only.

• Freight is included to authorized Gary Woodpecker only.

• Additional on-forwarding charges will apply for on-site delivery.